(a) Any retainage provided for in this section or requested to be withheld by the contractor shall be held by the procurement officer.
lawyer at desk

Ask a legal question, get an answer ASAP!
Click here to chat with a lawyer about your rights.

Terms Used In Hawaii Revised Statutes 103-32.1

  • Contract: A legal written agreement that becomes binding when signed.
  • county: includes the city and county of Honolulu. See Hawaii Revised Statutes 1-22
  • Damages: Money paid by defendants to successful plaintiffs in civil cases to compensate the plaintiffs for their injuries.
  • Evidence: Information presented in testimony or in documents that is used to persuade the fact finder (judge or jury) to decide the case for one side or the other.
  • Obligation: An order placed, contract awarded, service received, or similar transaction during a given period that will require payments during the same or a future period.
(b) A dispute between a contractor and subcontractor of any tier shall not constitute a dispute to which the State or any county is a party, and there is no right of action against the State or any county. The State and a county may not be interpleaded in any judicial or administrative proceeding involving such a dispute.
(c) Any public contract may include a provision for the retainage of a portion of the amount due under the contract to the contractor to ensure the proper performance of the contract; provided that:

(1) The sum withheld by the procurement officer from the contractor shall not exceed five per cent of the total amount due the contractor and that, after fifty per cent of the contract is completed and progress is satisfactory, no additional sum shall be withheld; provided further that if progress is not satisfactory, the procurement officer may continue to withhold, as retainage, sums not exceeding five per cent of the amount due the contractor; and
(2) The retainage shall not include sums deducted as liquidated damages from moneys due or that may become due the contractor under the contract.
(d) Where a subcontractor has provided evidence to the contractor of:

(1) A valid performance and a payment bond for the project that is acceptable to the contractor and executed by a surety company authorized to do business in this State;
(2) Any other bond acceptable to the contractor; or the retention amount withheld by the contractor from its subcontractor shall be not more than the same percentage of retainage as that of the contractor. This subsection shall also apply to the subcontractors who subcontract work to other subcontractors.
(3) Any other form of collateral acceptable to the contractor,
(e) This section shall not be construed to impair the right of a contractor or a subcontractor at any tier to negotiate, and to include in their subcontract, provisions that:

(1) Permit the contractor or subcontractor to retain, without cause, a specified percentage of no more than ten per cent of each progress payment otherwise due to a subcontractor for satisfactory performance under the subcontract, without incurring any obligation to pay a late payment interest penalty, in accordance with terms and conditions agreed to by the parties to the subcontract, giving such recognition as the parties deem appropriate to the ability of a subcontractor to furnish a performance bond and a payment bond, subject however, to the limitations of subsection (d); and
(2) Permit the contractor or subcontractor to make a determination that part or all of the subcontractor’s payment request may be withheld by the procurement officer in accordance with the subcontract agreement, without incurring any obligation to pay interest or a late payment penalty if a written notice of any withholding is issued to a subcontractor, with a copy to the procurement officer, specifying the following:

(A) The amount to be withheld;
(B) The specific causes for the withholding under the terms of the subcontract; and
(C) The remedial actions to be taken by the subcontractor to receive payment of the amounts withheld.
(f) A contractor may not request payment from the procurement officer of any amount withheld or retained in accordance with subsection (e) until such time as the contractor has determined and certified to the procurement officer that the subcontractor is entitled to the payment of such amount.
(g) The provisions of this section shall not be construed to require payment to subcontractors of retainage released to a contractor pursuant to an agreement entered into with the procurement officer meeting the requirements of section 103-32.2.

  Previous
Next  
 Part II Contents