Link to an amendment published at 89 FR 1815, Jan. 11, 2024.

(a) The Contract Work Hours and Safety Standards Act requires that laborers or mechanics shall be paid wages at a rate not less than one and one-half times the basic rate of pay for all hours worked in excess of forty hours in any workweek. In the event of violation of this provision, the contractor and any subcontractor shall be liable for the unpaid wages and in addition for liquidated damages, computed with respect to each laborer or mechanic employed in violation of the Act in the amount of $31 for each calendar day in the workweek on which such individual was required or permitted to work in excess of forty hours without payment of required overtime wages. Any contractor of subcontractor aggrieved by the withholding of liquidated damages shall have the right to appeal to the head of the agency of the United States (or the territory of District of Columbia, as appropriate) for which the contract work was performed or for which financial assistance was provided.

Need help with an employment contract?
Have it reviewed by a lawyer, get answers to your questions and move forward with confidence.
Connect with a lawyer now

Terms Used In 29 CFR 5.8

  • Administrator: means the Administrator of the Wage and Hour Division, U. See 29 CFR 5.2
  • agency: means any Federal, State, or local government agency or instrumentality, or other similar entity, that enters into a contract or provides assistance through loan, grant, loan guarantee or insurance, or otherwise, to a project subject to the Davis-Bacon labor standards, as defined in this section. See 29 CFR 5.2
  • Agency Head: means the principal official of an agency and includes those persons duly authorized to act on behalf of the Agency Head. See 29 CFR 5.2
  • Amendment: A proposal to alter the text of a pending bill or other measure by striking out some of it, by inserting new language, or both. Before an amendment becomes part of the measure, thelegislature must agree to it.
  • Appeal: A request made after a trial, asking another court (usually the court of appeals) to decide whether the trial was conducted properly. To make such a request is "to appeal" or "to take an appeal." One who appeals is called the appellant.
  • Contract: A legal written agreement that becomes binding when signed.
  • contract: means any prime contract which is subject wholly or in part to the labor standards provisions of any of the laws referenced by § 5. See 29 CFR 5.2
  • contractor: means any individual or other legal entity that enters into or is awarded a contract that is subject wholly or in part to the labor standards provisions of any of the laws referenced by § 5. See 29 CFR 5.2
  • Damages: Money paid by defendants to successful plaintiffs in civil cases to compensate the plaintiffs for their injuries.
  • laborer or mechanic: includes at least those workers whose duties are manual or physical in nature (including those workers who use tools or who are performing the work of a trade), as distinguished from mental or managerial. See 29 CFR 5.2
  • Secretary: includes the Secretary of Labor, and their authorized representative. See 29 CFR 5.2
  • subcontractor: means any contractor that agrees to perform or be responsible for the performance of any part of a contract that is subject wholly or in part to the labor standards provisions of any of the laws referenced in § 5. See 29 CFR 5.2
  • wages: means the basic hourly rate of pay; any contribution irrevocably made by a contractor or subcontractor to a trustee or to a third person pursuant to a bona fide fringe benefit fund, plan, or program; and the rate of costs to the contractor or subcontractor which may be reasonably anticipated in providing bona fide fringe benefits to laborers and mechanics pursuant to an enforceable commitment to carry out a financially responsible plan or program, which was communicated in writing to the laborers and mechanics affected. See 29 CFR 5.2

(b) Findings and recommendations of the Agency Head. The Agency Head has the authority to review the administrative determination of liquidated damages and to issue a final order affirming the determination. It is not necessary to seek the concurrence of the Administrator but the Administrator shall be advised of the action taken. Whenever the Agency Head finds that a sum of liquidated damages administratively determined to be due is incorrect or that the contractor or subcontractor violated inadvertently the provisions of the Act notwithstanding the exercise of due care upon the part of the contractor or subcontractor involved, and the amount of the liquidated damages computed for the contract is in excess of $500, the Agency Head may make recommendations to the Secretary that an appropriate adjustment in liquidated damages be made or that the contractor or subcontractor be relieved of liability for such liquidated damages. Such findings with respect to liquidated damages shall include findings with respect to any wage underpayments for which the liquidated damages are determined.

(c) The recommendations of the Agency Head for adjustment or relief from liquidated damages under paragraph (a) of this section shall be reviewed by the Administrator or an authorized representative who shall issue an order concurring in the recommendations, partially concurring in the recommendations, or rejecting the recommendations, and the reasons therefor. The order shall be the final decision of the Department of Labor, unless a petition for review is filed pursuant to part 7 of this title, and the Administrative Review Board in its discretion reviews such decision and order; or, with respect to contracts subject to the Service Contract Act, unless petition for review is filed pursuant to part 8 of this title, and the Administrative Review Board in its discretion reviews such decision and order.

(d) Whenever the Agency Head finds that a sum of liquidated damages administratively determined to be due under section 104(a) of the Contract Work Hours and Safety Standards Act for a contract is $500 or less and the Agency Head finds that the sum of liquidated damages is incorrect or that the contractor or subcontractor violated inadvertently the provisions of the Contract Work Hours and Safety Standards Act notwithstanding the exercise of due care upon the part of the contractor or subcontractor involved, an appropriate adjustment may be made in such liquidated damages or the contractor or subcontractor may be relieved of liability for such liquidated damages without submitting recommendations to this effect or a report to the Department of Labor. This delegation of authority is made under section 105 of the Contract Work Hours and Safety Standards Act and has been found to be necessary and proper in the public interest to prevent undue hardship and to avoid serious impairment of the conduct of Government business.

[48 FR 19541, Apr. 29, 1983, as amended at 51 FR 12265, Apr. 9, 1986; 51 FR 13496, Apr. 21, 1986; 81 FR 43450, July 1, 2016; 83 FR 12, Jan. 2, 2018; 84 FR 218, Jan. 23, 2019; 87 FR 2334, Jan. 14, 2022; 88 FR 2215, Jan. 13, 2023]