California Labor Code 1773.35 – (a) (1) A development proponent shall provide notice to the …
(a) (1) A development proponent shall provide notice to the Department of Industrial Relations of any contract to perform work subject to the requirements of Section 65852.24, 65912.130, 65912.131, or 65913.4 of the Government Code, within 30 days of the award, but in no event later than the first day in which a contractor has workers employed upon the project or development.
(2) The notice shall be transmitted electronically in a format specified by the department and shall include the name and registration number issued by the Department of Industrial Relations pursuant to Section 1725.6 of the contractor, the name and registration number issued by the Department of Industrial Relations pursuant to Section 1725.6 of any subcontractor listed on the contract, the bid and contract award dates, the estimated start and completion dates, jobsite location, and any additional information the department specifies that aids in the administration and enforcement of the requirements in Section 65852.24, 65912.130, 65912.131, or 65913.4 of the Government Code.
Terms Used In California Labor Code 1773.35
- Appeal: A request made after a trial, asking another court (usually the court of appeals) to decide whether the trial was conducted properly. To make such a request is "to appeal" or "to take an appeal." One who appeals is called the appellant.
- Contract: A legal written agreement that becomes binding when signed.
- Department: means Department of Industrial Relations. See California Labor Code 19
- Labor Commissioner: means Chief of the Division of Labor Standards Enforcement. See California Labor Code 21
- public works: means all of the following:
California Labor Code 1720
- Violation: includes a failure to comply with any requirement of the code. See California Labor Code 22
(b) In lieu of responding to any specific request for contract award information, the department may make the information provided by development proponents pursuant to this section available for public review on its internet website.
(c) (1) A developer or development proponent that fails to provide the notice required by subdivision (a) or that enters into a contract with or permits an unregistered contractor or subcontractor to engage in the performance of perform work subject to the requirements of Section 65852.24, 65912.130, 65912.131, or 65913.4 of the Government Code in violation of the requirements of Section 1725.6, shall, in addition to any other sanction or penalty authorized by law, be subject to a civil penalty of one hundred dollars ($100) for each day in violation of either requirement, not to exceed an aggregate penalty of ten thousand dollars ($10,000) for each project or development.
(2) The Labor Commissioner shall use the same standards specified in subparagraph (A) of paragraph (2) of subdivision (a) of Section 1775 when determining the severity of the violation and what penalty to assess, and may waive the penalty for a first time violation that was unintentional and did not hinder the Labor Commissioner’s ability to monitor and enforce compliance with the requirements of this chapter or Section 65852.24, 65912.130, 65912.131, or 65913.4 of the Government Code.
(d) A developer or development proponent shall withhold final payment due to the contractor until at least 30 days after all of the required information in paragraph (2) of subdivision (a) has been submitted, including, but not limited to, providing a complete list of all subcontractors. If a developer or development proponent makes a final payment to a contractor after that time and an unregistered contractor or subcontractor is found to have worked on the project, the developer or development proponent shall be subject to a civil penalty assessed by the Labor Commissioner of one hundred dollars ($100) for each full calendar day of noncompliance, for a period of up to 100 days, for each unregistered contractor or subcontractor.
(e) The Labor Commissioner may issue a citation for civil penalties to the developer or development proponent pursuant to subdivisions (c) and (d). The citation shall be served pursuant to § 1013 of the Code of Civil Procedure by first-class and certified mail.
(f) The procedure for the processing and appeal of a citation or civil penalty issued by the Labor Commissioner pursuant to this section shall be the same as that prescribed in Section 1023. For these purposes, “person” as used in Section 1023 shall include a developer or development proponent.
(g) A contractor or subcontractor shall not be liable for any penalties assessed against a developer or development proponent pursuant to this section. A developer or development proponent may not require a contractor or subcontractor to indemnify or otherwise be liable for any penalties assessed against a developer or development proponent pursuant to this section.
(h) Penalties received pursuant to this section shall be deposited in the State Public Works Enforcement Fund established by Section 1771.3 and shall be used only for the purposes specified in that section.
(Added by Stats. 2023, Ch. 39, Sec. 29. (AB 130) Effective July 10, 2023.)