Every contract shall contain a provision in regard to the time when the whole or any specified portion of the work contemplated shall be completed, and shall provide that for each day completion is delayed beyond the specified time, the contractor shall forfeit and pay to the state a specified sum of money, to be deducted from any payments due or to become due to the contractor. The sum so specified is valid as liquidated damages unless manifestly unreasonable under the circumstances existing at the time the contract was made. A contract for a road project, flood control project, or project involving facilities of the State Water Resources Development System may also provide for the payment of extra compensation to the contractor, as a bonus for completion prior to the specified time, the provision, if used, to be included in the specifications and to clearly set forth the basis for the payment.

(Amended by Stats. 1990, Ch. 1044, Sec. 1.5. Effective September 19, 1990.)

Terms Used In California Public Contract Code 10226

  • Contract: A legal written agreement that becomes binding when signed.
  • Damages: Money paid by defendants to successful plaintiffs in civil cases to compensate the plaintiffs for their injuries.
  • project: includes the erection, construction, alteration, repair, or improvement of any state structure, building, road, or other state improvement of any kind that will exceed a total cost calculated pursuant to subdivision (b). See California Public Contract Code 10105