Terms Used In 12 Guam Code Ann. § 83107

  • Contract: A legal written agreement that becomes binding when signed.
  • Damages: Money paid by defendants to successful plaintiffs in civil cases to compensate the plaintiffs for their injuries.
  • Public law: A public bill or joint resolution that has passed both chambers and been enacted into law. Public laws have general applicability nationwide.
(a) The contractor/developer shall build the Guam Twenty- First Century Healthcare Center in accordance with the Guam Building Code under Chapter 67 of Title 21, Guam Code Ann., and any other applicable requirements. The construction contract shall contain contractual obligations typically found in Government of Guam construction contracts, including, but not limited to:

COL 7/27/2023

12 Guam Code Ann. AUTONOMOUS AGENCIES
CH. 83 THE GUAM TWENTY-FIRST (21ST) CENTURY
HEALTHCARE CENTER ACT OF 2021

(1) warranties;

(2) liquidated damages;

(3) performance and payments bonds; (4) indemnity;
(5) insurance;

(6) standard specifications; (7) technical specifications; (8) progress schedule;
(9) maintenance;

(10) compliance with Guam labor regulations;

(11) compliance with Guam prevailing wage rates for employment of temporary alien workers (H2) on Guam;

(12) compliance with Public Law 28-98: restriction against contractors employing convicted sex offenders to work at Government of Guam venues; and

(13) the 2017 Guam Tropical Energy Code.

(b) The contract must be approved as to form and legality by the Attorney General of Guam.

2022 NOTE: Subsection designations added/altered pursuant to the authority of 1 Guam Code Ann. § 1606.

  Previous section
Next section  
 Chapter 83 Contents