Louisiana Revised Statutes > Title 38 > Chapter 10 > Part III – Claims of Subcontractors, Materialmen, and Laborers On Public Works
Current as of: 2023 | Check for updates
|
Other versions
Terms Used In Louisiana Revised Statutes > Title 38 > Chapter 10 > Part III - Claims of Subcontractors, Materialmen, and Laborers On Public Works
- Claimant: as used in this Chapter , means any person to whom money is due pursuant to a contract with the owner or a contractor or subcontractor for doing work, performing labor, or furnishing materials or supplies for the construction, alteration, or repair of any public works, or for transporting and delivering such materials or supplies to the site of the job by a for-hire carrier, or for furnishing oil, gas, electricity, or other materials or supplies for use in machines used in the construction, alteration, or repair of any public works, including persons to whom money is due for the lease or rental of movable property used at the site of the immovable and leased to the owner, contractor, or subcontractor by written contract, and including registered or certified surveyors or engineers or consulting engineers, or licensed architects, or their professional subconsultants employed by the owner or by the contractor or subcontractor in connection with the building of any public work. See Louisiana Revised Statutes 38:2242
- Clerk of court: An officer appointed by the court to work with the chief judge in overseeing the court's administration, especially to assist in managing the flow of cases through the court and to maintain court records.
- Damages: Money paid by defendants to successful plaintiffs in civil cases to compensate the plaintiffs for their injuries.
- Emergency: means an unforeseen mischance bringing with it destruction or injury of life or property or the imminent threat of such destruction or injury or as the result of an order from any judicial body to take any immediate action which requires construction or repairs absent compliance with the formalities of this Part, where the mischance or court order will not admit of the delay incident to advertising as provided in this Part. See Louisiana Revised Statutes 38:2211
- Federal Deposit Insurance Corporation: A government corporation that insures the deposits of all national and state banks that are members of the Federal Reserve System. Source: OCC
- Lease: A contract transferring the use of property or occupancy of land, space, structures, or equipment in consideration of a payment (e.g., rent). Source: OCC
- Lien: A claim against real or personal property in satisfaction of a debt.
- Mortgage: The written agreement pledging property to a creditor as collateral for a loan.
- Obligation: An order placed, contract awarded, service received, or similar transaction during a given period that will require payments during the same or a future period.
- Plaintiff: The person who files the complaint in a civil lawsuit.
- Power of attorney: A written instrument which authorizes one person to act as another's agent or attorney. The power of attorney may be for a definite, specific act, or it may be general in nature. The terms of the written power of attorney may specify when it will expire. If not, the power of attorney usually expires when the person granting it dies. Source: OCC
- Public work: means the erection, construction, alteration, improvement, or repair of any public facility or immovable property owned, used, or leased by a public entity. See Louisiana Revised Statutes 38:2211
- Trial: A hearing that takes place when the defendant pleads "not guilty" and witnesses are required to come to court to give evidence.
- Writ: A formal written command, issued from the court, requiring the performance of a specific act.