The United States Court of Federal Claims shall have jurisdiction to render judgment upon any claim for liquidated damages withheld from a contractor or subcontractor under section 3703 of title 40.

Terms Used In 28 USC 1499

  • Damages: Money paid by defendants to successful plaintiffs in civil cases to compensate the plaintiffs for their injuries.
  • Jurisdiction: (1) The legal authority of a court to hear and decide a case. Concurrent jurisdiction exists when two courts have simultaneous responsibility for the same case. (2) The geographic area over which the court has authority to decide cases.
  Previous section
Next section  
 Chapter 91 Contents