Texas Transportation Code 315.095 – Suspension of Work
Current as of: 2024 | Check for updates
|
Other versions
Terms Used In Texas Transportation Code 315.095
- Appellate: About appeals; an appellate court has the power to review the judgement of another lower court or tribunal.
When suit is brought under Section 315.092, the municipality or the contractor may suspend performance of work until a final judgment is rendered in the case and all appellate remedies are exhausted.