Ask a legal question, get an answer ASAP!
Click here to chat with a lawyer about your rights.

Terms Used In New Jersey Statutes 40A:11-19

  • Contract: A legal written agreement that becomes binding when signed.
  • Damages: Money paid by defendants to successful plaintiffs in civil cases to compensate the plaintiffs for their injuries.
  • person: includes corporations, companies, associations, societies, firms, partnerships and joint stock companies as well as individuals, unless restricted by the context to an individual as distinguished from a corporate entity or specifically restricted to one or some of the above enumerated synonyms and, when used to designate the owner of property which may be the subject of an offense, includes this State, the United States, any other State of the United States as defined infra and any foreign country or government lawfully owning or possessing property within this State. See New Jersey Statutes 1:1-2
19. Any contract made pursuant to P.L.1971, c.198 (C. 40A:11-1 et seq.) may include liquidated damages for the violation of any of the terms and conditions thereof or the failure to perform said contract in accordance with its terms and conditions, or the terms and conditions of P.L.1971, c.198 (C. 40A:11-1 et seq.). Notwithstanding any other provision of law to the contrary, it shall be void, unenforceable and against public policy for a provision in a contract entered into under P.L.1971, c.198 (C. 40A:11-1 et seq.) to limit a contractor’s remedy for the contracting unit’s negligence, bad faith, active interference, tortious conduct, or other reasons uncontemplated by the parties that delay the contractor’s performance, to giving the contractor an extension of time for performance under the contract. For the purposes of this section, “contractor” means a person, his assignees or legal representatives with whom a contract with a contracting unit is made.

L.1971,c.198,s.19; amended 1999, c.440, s.28; 2001, c.206, s.1.