Wisconsin Statutes 779.135 – Construction contracts, form of contract
Current as of: 2023 | Check for updates
|
Other versions
The following provisions in contracts for the improvement of land in this state are void:
Terms Used In Wisconsin Statutes 779.135
- Contract: A legal written agreement that becomes binding when signed.
- Following: when used by way of reference to any statute section, means the section next following that in which the reference is made. See Wisconsin Statutes 990.01
- Land: includes lands, tenements and hereditaments and all rights thereto and interests therein. See Wisconsin Statutes 990.01
- Lien: A claim against real or personal property in satisfaction of a debt.
- Litigation: A case, controversy, or lawsuit. Participants (plaintiffs and defendants) in lawsuits are called litigants.
- Person: includes all partnerships, associations and bodies politic or corporate. See Wisconsin Statutes 990.01
- Precedent: A court decision in an earlier case with facts and law similar to a dispute currently before a court. Precedent will ordinarily govern the decision of a later similar case, unless a party can show that it was wrongly decided or that it differed in some significant way.
- State: when applied to states of the United States, includes the District of Columbia, the commonwealth of Puerto Rico and the several territories organized by Congress. See Wisconsin Statutes 990.01
(1) Provisions requiring any person entitled to a construction lien to waive his or her right to a construction lien or to a claim against a payment bond before he or she has been paid for the labor, services, materials, plans, or specifications that he or she performed, furnished, or procured.
(2) Provisions making the contract subject to the laws of another state or requiring that any litigation, arbitration or other dispute resolution process on the contract occur in another state.
(3) Provisions making a payment to a prime contractor from any person who does not have a contractual agreement with the subcontractor, supplier, or service provider a condition precedent to a prime contractor’s payment to a subcontractor, supplier, or service provider. This subsection does not prohibit contract provisions that may delay a payment to a subcontractor until the prime contractor receives payment from any person who does not have a contractual agreement with the subcontractor, supplier, or service provider.