No action to recover damages for any injury to property, real or personal, or for injury to the person, or for bodily injury or wrongful death, arising out of the defective or unsafe condition of a physical improvement to real property, nor any action for contribution or indemnity for damages so sustained, against any person performing or furnishing the construction or the design, planning, supervision, inspection or administration of construction of such improvement to real property, and on account of such activity, shall be brought after ten years from the date of substantial completion of such improvement; provided this limitation shall not apply to any action based on a contract, warranty or guarantee which contains express terms inconsistent herewith. The date of substantial completion shall mean the date when construction is sufficiently completed so that the owner can occupy or use the improvement for the purpose for which it was intended, or the date on which the owner does so occupy or use the improvement, or the date established by the contractor as the date of substantial completion, whichever date occurs last.

Terms Used In New Mexico Statutes 37-1-27

  • Contract: A legal written agreement that becomes binding when signed.
  • Damages: Money paid by defendants to successful plaintiffs in civil cases to compensate the plaintiffs for their injuries.
  • Real property: Land, and all immovable fixtures erected on, growing on, or affixed to the land.