(1) Persons engaged in any activity defined in RCW 4.16.300 may be excused, in whole or in part, from any obligation, damage, loss, or liability for those defined activities under the principles of comparative fault for the following affirmative defenses:

Terms Used In Washington Code 4.16.326

  • Contract: A legal written agreement that becomes binding when signed.
  • Damages: Money paid by defendants to successful plaintiffs in civil cases to compensate the plaintiffs for their injuries.
  • Discovery: Lawyers' examination, before trial, of facts and documents in possession of the opponents to help the lawyers prepare for trial.
  • Obligation: An order placed, contract awarded, service received, or similar transaction during a given period that will require payments during the same or a future period.
  • person: may be construed to include the United States, this state, or any state or territory, or any public or private corporation or limited liability company, as well as an individual. See Washington Code 1.16.080
  • Statute: A law passed by a legislature.
  • Statute of limitations: A law that sets the time within which parties must take action to enforce their rights.
  • Tort: A civil wrong or breach of a duty to another person, as outlined by law. A very common tort is negligent operation of a motor vehicle that results in property damage and personal injury in an automobile accident.
(a) To the extent it is caused by an unforeseen act of nature that caused, prevented, or precluded the activities defined in RCW 4.16.300 from meeting the applicable building codes, regulations, and ordinances in effect at the commencement of construction. For purposes of this section an “unforeseen act of nature” means any weather condition, earthquake, or man-made event such as war, terrorism, or vandalism;
(b) To the extent it is caused by a homeowner’s unreasonable failure to minimize or prevent those damages in a timely manner, including the failure of the homeowner to allow reasonable and timely access for inspections and repairs under this section. This includes the failure to give timely notice to the builder after discovery of a violation, but does not include damages due to the untimely or inadequate response of a builder to the homeowner’s claim;
(c) To the extent it is caused by the homeowner or his or her agent, employee, subcontractor, independent contractor, or consultant by virtue of their failure to follow the builder’s or manufacturer’s maintenance recommendations, or commonly accepted homeowner maintenance obligations. In order to rely upon this defense as it relates to a builder’s recommended maintenance schedule, the builder shall show that the homeowner had written notice of the schedule, the schedule was reasonable at the time it was issued, and the homeowner failed to substantially comply with the written schedule;
(d) To the extent it is caused by the homeowner or his or her agent’s or an independent third party’s alterations, ordinary wear and tear, misuse, abuse, or neglect, or by the structure’s use for something other than its intended purpose;
(e) As to a particular violation for which the builder has obtained a valid release;
(f) To the extent that the builder’s repair corrected the alleged violation or defect;
(g) To the extent that a cause of action does not accrue within the statute of repose pursuant to RCW 4.16.310 or that an actionable cause as set forth in RCW 4.16.300 is not filed within the applicable statute of limitations. In contract actions the applicable contract statute of limitations expires, regardless of discovery, six years after substantial completion of construction, or during the period within six years after the termination of the services enumerated in RCW 4.16.300, whichever is later;
(h) As to any causes of action to which this section does not apply, all applicable affirmative defenses are preserved.
(2) This section does not apply to any civil action in tort alleging personal injury or wrongful death to a person or persons resulting from a construction defect.