1.  No action may be commenced against the owner, occupier or any person performing or furnishing the design, planning, supervision or observation of construction, or the construction of an improvement to real property more than 10 years after the substantial completion of such an improvement, for the recovery of damages for:

Terms Used In Nevada Revised Statutes 11.202

  • Damages: Money paid by defendants to successful plaintiffs in civil cases to compensate the plaintiffs for their injuries.
  • Fraud: Intentional deception resulting in injury to another.
  • person: means a natural person, any form of business or social organization and any other nongovernmental legal entity including, but not limited to, a corporation, partnership, association, trust or unincorporated organization. See Nevada Revised Statutes 0.039
  • Personal property: All property that is not real property.
  • Real property: Land, and all immovable fixtures erected on, growing on, or affixed to the land.

(a) Except as otherwise provided in subsection 2, any deficiency in the design, planning, supervision or observation of construction or the construction of such an improvement;

(b) Injury to real or personal property caused by any such deficiency; or

(c) Injury to or the wrongful death of a person caused by any such deficiency.

2.  Except as otherwise provided in this subsection, an action may be commenced against the owner, occupier or any person performing or furnishing the design, planning, supervision or observation of construction, or the construction of an improvement to real property at any time after the substantial completion of such an improvement, for the recovery of damages for any act of fraud in causing a deficiency in the design, planning, supervision or observation of construction or the construction of such an improvement. The provisions of this subsection do not apply to any lower-tiered subcontractor who performs work that covers up a defect or deficiency in another contractor’s trade if the lower-tiered subcontractor does not know, and should not reasonably know, of the existence of the alleged defect or deficiency at the time of performing such work. As used in this subsection, ‘lower-tiered subcontractor’ has the meaning ascribed to it in NRS 624.608.

3.  The provisions of this section do not apply:

(a) To a claim for indemnity or contribution.

(b) In an action brought against:

(1) The owner or keeper of any hotel, inn, motel, motor court, boardinghouse or lodging house in this State on account of his or her liability as an innkeeper.

(2) Any person on account of a defect in a product.

  Previous section
Next section  
 Actions Other Than for the Recovery of Real Property Contents